文档介绍：该【工程承包合同书英语(2025版) 】是由【金】上传分享，文档一共【20】页，该文档可以免费在线阅读，需要了解更多关于【工程承包合同书英语(2025版) 】的内容，可以使用淘豆网的站内搜索功能，选择自己适合的文档，以下文字是截取该文章内的部分文字，如需要获得完整电子版，请下载此文档到您的设备，方便您编辑和打印。甲 方： XXX
乙 方： XXX
20XX
COUNTRACT COVER
专业合同封面
RESUME
PERSONAL
工程承包合同书英语(2025版)
本合同目录一览
1. Contract Parties
Party A Information
Party B Information
2. Scope of Work
General Description
Specific Tasks
3. Project Duration and Schedule
Start Date
Completion Date
Milestones
4. Payment Terms
Payment Schedule
Payment Methods
Retention
5. Contract Price
Fixed Price
Cost Plus
Other Pricing Terms
6. Materials and Equipment
Materials
Equipment
Supplier Requirements
7. Quality Control
Quality Standards
Inspection Procedures
Nonconforming Materials
8. Changes to the Work
Change Orders
Approval Process
Cost and Time Impact
9. Safety and Environmental Protection
Safety Requirements
Environmental Regulations
Compliance
10. Dispute Resolution
Mediation
Arbitration
Litigation
11. Insurance Requirements
General Liability
Worker's Compensation
Property Insurance
12. Termination of Contract
Conditions for Termination
Notice of Termination
Consequences of Termination
13. Confidentiality
Information Sharing
NonDisclosure Agreement
14. General Provisions
Governing Law
Force Majeure
Entire Agreement
Amendments and Modifications
第一部分：合同如下：
1. Contract Parties
Party A Information
Name: [Party A's Name]
Address: [Party A's Address]
Contact Person: [Party A's Contact Person]
Contact Information: [Party A's Contact Information]
Party B Information
Name: [Party B's Name]
Address: [Party B's Address]
Contact Person: [Party B's Contact Person]
Contact Information: [Party B's Contact Information]
2. Scope of Work
General Description
Project Name: [Project Name]
Project Location: [Project Location]
Project Description: [Detailed Description of the Project]
Specific Tasks
Task 1: [Description of Task 1]
Task 2: [Description of Task 2]
Task 3: [Description of Task 3]
Task 4: [Description of Task 4]
Task 5: [Description of Task 5]
3. Project Duration and Schedule
Start Date: [Start Date]
Completion Date: [Completion Date]
Milestones
Milestone 1: [Description of Milestone 1]
Milestone 2: [Description of Milestone 2]
Milestone 3: [Description of Milestone 3]
Milestone 4: [Description of Milestone 4]
Milestone 5: [Description of Milestone 5]
4. Payment Terms
Payment Schedule
Payment 1: [Amount and Date]
Payment 2: [Amount and Date]
Payment 3: [Amount and Date]
Payment 4: [Amount and Date]
Final Payment: [Amount and Date]
Payment Methods
Wire Transfer
Check
Credit Card
Retention
Amount: [Percentage or Fixed Amount]
Release Conditions: [Conditions for Retention Release]
5. Contract Price
Fixed Price
Total Contract Price: [Fixed Price Amount]
Inclusion of Costs: [List of Included Costs]
Exclusion of Costs: [List of Excluded Costs]
Cost Plus
Cost Estimate: [Estimated Cost Amount]
Markup Percentage: [Percentage Added to Costs]
Other Pricing Terms
Time and Materials
Unit Price
6. Materials and Equipment
Materials
List of Materials: [Detailed List of Materials]
Quality Requirements: [Quality Standards for Materials]
Equipment
List of Equipment: [Detailed List of Equipment]
Maintenance Requirements: [Maintenance Procedures for Equipment]
7. Quality Control
Quality Standards
National Standards: [Applicable National Standards]
Industry Standards: [Applicable Industry Standards]
Inspection Procedures
PreConstruction Inspections
During Construction Inspections
Final Inspections
Nonconforming Materials
Identification of Nonconforming Materials
Immediate Removal
Replacement Procedures
8. Changes to the Work
Change Orders
Request for Change: [Process for Submitting a Change Request]
Approval Process: [Steps for Approving a Change]
Approval Process
Party A Approval: [Process for Party A's Approval]
Party B Approval: [Process for Party B's Approval]
Cost and Time Impact
Cost Impact Assessment: [Method for Assessing Cost Impact]
Time Impact Assessment: [Method for Assessing Time Impact]
9. Safety and Environmental Protection
Safety Requirements
Compliance with Local Laws: [Safety Regulations to Be Adhered To]
Safety Plan: [Detailed Safety Plan for the Project]
Environmental Regulations
Compliance with Environmental Laws: [Environmental Regulations to Be Followed]
Environmental Impact Assessment: [Assessment of Environmental Impact]
Compliance
Regular Audits: [Schedule for Environmental and Safety Audits]
Corrective Actions: [Steps to Be Taken for NonCompliance]
10. Dispute Resolution
Mediation
Appointment of Mediator: [Process for Appointing a Mediator]
Mediation Process: [Detailed Steps of the Mediation Process]
Arbitration
Arbitration Agreement: [Terms of Arbitration]
Arbitration Procedure: [Steps to Follow in Arbitration]
Litigation
Jurisdiction: [Legal Jurisdiction for Litigation]
11. Insurance Requirements
General Liability
Insurance Coverage: [Minimum Coverage Amount]
Insurance Policy: [Details of Insurance Policy]
Worker's Compensation
Coverage: [Worker's Compensation Coverage Requirements]